alert - warning

This page has not been translated into Español. Visit the Español page for resources in that language.

Additional Costs for Steam Line Repair

Appeal Brief Appeal Letter

Appeal Brief

DesastreFEMA-1174-DR
ApplicantUniversity of North Dakota
Appeal TypeSecond
PA ID#000-92004
PW ID#60254 and 74857
Date Signed2008-08-11T04:00:00
Citation: FEMA-1174-DR-ND, University of North Dakota (Applicant), Additional Costs for Steam Line Repair, DSRs 60254 and 64857

Cross-reference: Work Eligibility

Summary: The Applicant requested additional funding for additional costs resulting from: the Applicant’s decision to temporarily stop work, relocate a steam line to avoid
interference with extant utility lines, and realign a steam pipe and manhole dislodged because of subsidence.
The costs related to the stop-work order are not the result of the declared disaster and are not eligible costs under the Public Assistance Program. The stop-work order was an avoidable action. In addition, the re-grading of a steam line was the contractor’s responsibility as it failed to protect the construction site. The relocation of one steam line is eligible repair work. These costs are included in the eligible scope of work and are, therefore, eligible for funding.
Issues: 1. Are additional costs that result from administratively avoidable decisions not directly related to the disaster eligible for assistance?
2. Is the re-grading of a damaged steam line eligible?

3. Is the relocation the damaged steam line eligible?

Findings: 1. No.

2. No.
3. Yes.

Rationale: 44 CFR §206.223

Appeal Letter

August 11, 2008

Lonnie G. Hoffer
Alternate Governors Authorized Representative
Office of the Adjutant General
Department of Emergency Services
P.O. Box 5511
Bismarck, North Dakota 58506-5511

Re: Second Appeal–University of North Dakota, PA ID 000-92004
Additional Costs for Steam Line Repair, FEMA-1174-DR-ND
Damage Survey Report (DSR) 60254 and 64857

Dear Mr. Hoffer:

This letter is in response to your letter dated January 14, 2008, which transmitted the referenced second appeal on behalf of the University of North Dakota (Applicant). The Applicant is appealing the Department of Homeland Security’s Federal Emergency Management Agency’s (FEMA) denial of funding for additional costs for steam line repair on the Applicant’s campus.

The flood of the Red River and its tributaries in April 1997 damaged large portions of the Applicant’s campus. FEMA prepared DSR 59315 to replace the damaged underground steam distribution system. The Applicant’s contractor began work on the project on April 19, 1999. On August 29, 1999, the Applicant issued a stop-work order to the contractor, because the Applicant had not obtained the required easement to complete the project. The contractor did not work on the project from August 1999 to March 2000. The Applicant’s contract contained a provision that required the Applicant to pay the contractor a penalty if the Applicant stopped work on the project.
The Applicant’s contractor was awarded $999,999 for additional work and the work stoppage in an arbitration settlement agreement. The Applicant requested reimbursement from FEMA. FEMA reviewed the costs for the additional work and found eligible costs in the amount of $68,417 (DSR 60254). However, FEMA denied $430,408 associated with the work stoppage, because the stop-work order was issued for the convenience of the Applicant and the costs were not directly a result of the disaster. The Applicant appealed for additional funding. The Region VIII Response and Recovery Director reviewed the request, rationale, and documentation and found additional eligible costs in the amount of $21,824 (DSR 64857), but sustained the earlier decision on the costs for the work stoppage.

The Applicant filed a second appeal by letter dated January 7, 2007 [sic 2008]. The second appeal claimed the $430,408 associated with the stop-work order. The Applicant stated that the lack of easements to the Newman Center resulted in the stop-work order. The Applicant contended that the delay was a legal necessity and that since the contract explicitly entitled the contractor to damages resulting from owner-caused delays, the additional costs should be eligible FEMA costs. In addition, the Applicant stated that additional easements with third parties were needed to complete the project. The Applicant also alluded to the potential for underground conditions that could have delayed the project. However, the Applicant did not provide information to support that underground conditions were the reason for the delay.
FEMA does not dispute the fact that the contract required the Applicant to pay the contractor for any work stoppage on the project. The Applicant stopped work on the project because it did not obtain the necessary easements to complete the job. The Applicant could have avoided this action by appropriately planning for the project. Penalty costs related to non-compliance with provisions of executed contracts are not eligible for reimbursement under the Public Assistance Program. These costs were not incurred in the performance of eligible work. Therefore, the Applicant’s request for reimbursement of these costs is denied.
The applicant also requested $26,421 for work to adjust the grade of a steam line after the excavation trench was inundated by non-disaster related flooding. The applicant claims the damage was due to a pre-existing condition below the compacted soil. However, the information provided by the applicant’s architect states that the most likely cause was flooding of the trench and the construction operations. It was the contractor’s responsibility to protect the construction site. Therefore, this cost is not eligible for funding.

The second appeal also requested $26,024 for re-routing a steam line. We have determined this is an eligible repair cost. These costs are included in the eligible scope of work and are, therefore, eligible for funding. Accordingly, I am requesting that the Regional Administrator prepare a supplement DSR for $26,024 to implement this decision.
Please inform the Applicant of my decision. This determination is the final decision on this matter pursuant to 44 CFR §206.206.

Sincerely,
/s/
Carlos J. Castillo
Assistant Administrator
Disaster Assistance Directorate

cc: Douglas A. Gore
Acting Regional Administrator
FEMA Region VIII